Loading...
HomeMy WebLinkAboutbocc.con.046.2015 (2)Rev. 08-30-11 jls COUNTY CLERK'S CONTRACT COVERSHEET CONTRACT it: 046-2015 ORIGINATING DEPARTMENT: Airport PROCUREMENT OFFICER: Dustin Havel PHONE #: -4292855 PROJECT NAME: RW1S Maintenance CONTRACTOR: Vaisala Inc. DOLLAR AMOUNT: $8.050.00 LINE ITEM # 404.25.00000.82000 CONTRACT EXECUTION DATE: 4/1/2015 CONTRACT END DATE: 3/30/2016 AUTOMATIC RENEWAL: ❑ YES ®NO TERM: ❑ BOCC AGENDA ITEM (Grants, IGA) ® STAFF AUTHORIZED SIGNATURE (Requires BOCC Signature) (Per Revised Procurement Code 7/2005) ❑ OVER $50,000 (Requires Section Leader & County Manager's Signature) ✓ CHECK PROCUREMENT TYPE: []None ❑ Informal ❑ Formal ® Sole Source ❑ Emergency ❑ Outside Agency/State Bid ❑ Compliance with C.R.S. 8-17-5-101, 102 as amended (Immigration Form) ❑ Exempt ❑ Contract Renewal ✓ CHECK CONTRACT TYPE: ® Services/Maintenance ❑ Employment ❑ License/Use ❑ Intergovernmental Agreement (Resolution Required) ❑ Lease ❑ Non -Profit ❑ Construction ❑ Quasi -Public (e.g: AVH) ❑ Goods, Equipment, Supplies ❑ Grant Agreements (Notify Finance & Resolution Required) ❑ Other (e.g. revenue) ❑ Change Order/Contract Amendment (C/O: 10% or $25K whichever is the lesser must have County Manager signature) All Contracts should be proofed and all exhibits and notices must be attached for the following: ✓ ® No Pages Missing ✓® All Other Blanks Filled In ✓ ® If Page Left Intentionally Blank —Note on Page ✓® All Exhibits Attached ✓ ® Page numbered consecutively ✓❑ All Legal Descriptions attached (if applicable) ✓ ® All Original Signatures Affixed ✓❑ Notice of Award/Notice to Proceed Attached (if applicable, ✓ ® All Dates Filled In ✓❑ Warranty (if applicable) ✓ ❑ Special Instructions for Finance Department: ✓ ® Authorized Procurement Officer's Name: Dustin Havel BY CHECKING ABOVE AND ENTERING NAME, THE AUTHORIZED STAFF PERSON INDICATES THAT THE ATTACHED DOCUMENT HAS BEEN PROOFED AND READY FOR SCANNING. NOTE: CLERK'S OFFICE WILL KEEP ORIGINAL DOCUMENTS IN COMPLIANCE WITH COLORADO STATE ARCHIVES RETAINAGE SCHEDULE. ALL ATTACHMENTS MUST BE WITH THIS CHECKLIST! Contract # 046-2015 Rev. 8.3 1.11 jaa/js Budget Line Item# 404.25.00000.82000 2/6/2012 m, G 0,fuDf% Coll! lei If a CONTRACT FOR PROVISION OF SERVICES RUNWAY WEATHER INFORMATION SYSTEM MAINTENANCE THIS CONTRACT is made and entered by and between the Pitkin County Board of County Commissioners ("County") and Vaisala Inc. 194 South Taylor Avenue in Louisville, CO 80027 (hereinafter "Contractor"). Term. The term of this contract is from April 1, 2015 to March 30, 2016. 2. Contractor's Oblieations. Contractor shall: Refer to Exhibit A and Attachment 2. If there is conflicting language in the Exhibit or the Attachment the contract will prevail. 3. Compensation and Expenses, Invoicing, Payment and Offset. The County shall compensate Contractor for its services in accordance with the Project Budget and Schedule set out in Paragraph 2. It is expressly understood and agreed that in no event will the total compensation and reimbursement to be paid hereunder exceed the sum of $8050.00 for all services rendered. By contract or amendment, the County and Contractor may reallocate the budget among project tasks if the total budget amount remains unchanged. Contractor shall invoice for the project monthly based on hours worked, with payment expected within thirty (30) days of invoice, but any payment by the County may be offset by any amount the Contractor owes the County for any reason. 4. County's Exclusive Ownership of Work Product. Drawings, specifications, guidelines and other documents prepared by Contractor in connection with this contract shall be the property of the County. However, Contractor shall have the right to utilize such documents in the course of its marketing, professional presentations, and for other business purposes. Contractor assigns to County the copyrights to all work prepared, developed, or created pursuant to this contract, including the right to: 1) reproduce the work; 2) prepare derivative works; 3) distribute copies to the public; 4) perform the works publicly; and 5) to display the work publicly. Contractor shall have right to use materials produced in the course of this contract for marketing purposes and professional presentations, articles, speeches and other business purposes. 5. Pitkin County's Obligations. Pitkin County shall administer this contract through a County Representative. Dustin Havel will manage the project as the County's Representative. In the event that Dustin Havel is not available, Fil Meraz shall assume the County Representative's duties. The services provided and products delivered by the Contractor under this contract will be subject to review by the County's Representatives, or a designee, for compliance with Contractor's obligations prior to final payment. Contract # 046-2015 Rev. 8.3 1.11 jaa/js Budget Line Item# 404.25.00000.82000 2/6/20121m 6. Termination Prior to Expiration of Contract Term. The County has the right to terminate this contract, with or without cause, by giving written notice to the Contractor of such termination and specifying the effective date thereof. Such notice shall be given at least ten (10) days before the effective date of such termination. In such event all finished or unfinished documents, data, studies and reports prepared by the Contractor pursuant to this contract shall become the County's property. Contractor shall be entitled to receive compensation in accordance with the contract for any satisfactory work completed pursuant to the terms of this contract prior to the date of termination. Notwithstanding the above, Contractor shall not be relieved of liability to the County for damages sustained by the County by virtue of any breach of the contract by the Contractor. 7. Independent Contractor Status. A. The parties to this contract intend that the relationship between them contemplated by the contract is that of independent contractor. Contractor, and any agent, employee, or servant of Contractor shall not be deemed to be an employee, agent, or servant of Pitkin County. B. Contractor is not required to offer his services exclusively to Pitkin County under this contract. Contractor may choose to work for other individuals or entities during the term of this contract, provided that the basic services and deliverable products required under this contract are submitted in the manner and on the schedule defined under this contract. C. Contractor warrants that all work produced will conform to all applicable industry standard of care, skill and diligence in the performance of Contractor's obligations under this contract. D. Contractor shall not attempt to oversee or supervise the work or actions of any Pitkin County employee, servant or agent in the course of completing work under this contract. E. Contractor is not entitled to any Workers' Compensation benefits through Pitkin County and is responsible for payment of any federal, state, FICA and other income taxes. 8 Assi ng ability. This contract is not assignable by either party. Any use of subcontractors by the Contractor for performance of this contract must be accepted in writing by the County. 9. Binding Arbitration. Any disputes arising out of this contract shall be subject to binding arbitration. The parties agree that any disputes concerning the terms and conditions of this contract shall be submitted and finally settled by arbitration. Arbitration shall be conducted pursuant to the rules of the American Arbitration Association and shall be presided over by the Pitkin County Hearing Officer appointed to arbitrate Pitkin County contract disputes. Costs of the arbitration shall be awarded to the substantially prevailing party. 10. Severability. In the event that any provision of this contract shalt be held to be invalid or unenforceable, the remaining provisions of this contract shall remain valid and binding upon the parties hereto 11. Integration and Modification. A. This contract represents the entire and integrated contract between the County and the Contractor and supersedes all prior negotiations, representations, or contract, either written or oral. This contract may be amended only by written contract signed by both the County and the Contractor. Contract # 046-2015 Rev. 8.3 1.11 jaa/js Budget Line Item# 404.25.00000.82000 2/6/2012 lin B. The County may, from time to time, request changes in the scope of services of the Contractor to be performed hereunder. Such changes, including the increase or decrease in the amount of the Contractor's compensation, which are mutually agreed upon between the County and the Contractor, shall be in writing and upon execution shall become part of this contract. 12. Indemnity. A. The Contractor agrees to indemnify, hold harmless and, not excluding the County's right to participate, defend the County, its subsidiary, parent, associated and/or affiliated entities, successors, or assigns, its elected officials, trustees, employees, agents, volunteers, and any jurisdiction or agency issuing permits for any work included in the project, hereinafter referred to as indemnitee, from all suits and claims, including attorney's fees and cost of litigation, actions, loss, damage, expense, cost or claims of any character or any nature arising out of the work done in fidfillment of the terms of this Contract or on account of any act, claim or amount arising or recovered under workers' compensation law or arising out of the failure of the Contractor to conform to any statutes, ordinances, regulation, law or court decree. It is agreed that the Contractor will be responsible for primary loss investigation, defense and judgment costs where this contract of indemnity applies. In consideration of the award of this contract, the Contractor agrees to waive all rights of subrogation against the County its subsidiary, parent, associated and/or affiliated entities, successors, or assigns, its elected officials, trustees, employees, agents, and volunteers for losses arising from the work performed by the Contractor for the County. B. The Contractor further shall investigate, process, respond to, adjust, provide defense for and defend, pay or settle all claims, demands, or lawsuits related hereto at its sole expense and shall bear all other costs and expenses related thereto, even if the claim, demand or lawsuit is groundless, false or fraudulent. 13. Insurance. Contractor and subcontractors shall procure and maintain until all of their obligations have been discharged, including any warranty periods under this Contract are satisfied, insurance against claims for injury to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, its agents, representatives, employees or subcontractors. The insurance requirements herein are minimum requirements for this Contract and in no way limit the indemnity covenants contained in this Contract. The County in no way warrants that the minimum limits contained herein are sufficient to protect the Contractor from liabilities that might arise out of the performance of the work under this Contract by the Contractor, its agents, representatives, employees, or subcontractors. The Contractor shall assess its own risks and if it deems appropriate and/or prudent, maintain higher limits and/or broader coverages. The Contractor is not relieved of any liability or other obligations assumed or pursuant to the Contract by reason of its failure to obtain or maintain insurance in sufficient amounts, duration, or types. A. Coverage and Limits of Insurance: Contractor shall provide coverage with limits of liability not less than those stated below. An umbrella and/or excess liability policy may be used to meet the minimum liability requirements provided that the coverage is written on a "following form" basis. Statutory Workers' Compensation: Colorado statutory minimums. 3 Contract # 046-2015 Budget Line Item# 404.25.00000.82000 Rev. 8.3 1.11 jaa/js 2/6/2012 Im a. Policy shall contain a waiver of subrogation against the County. b. This requirement shall not apply when a contractor or subcontractor is exempt under Colorado Workers' Compensation Act., AND when such contractor or subcontractor executes the appropriate Work Comp Waiver form. Minimum Limits: Coverage A (Workers' Compensation) Statutory Coverage B (Employers Liability) $ 500,000 $ 500,000 $ 500,000 2. Commercial General Liability —ISO 1 CG 0001 form or equivalent (With County named additional insured) Minimum Limits: General Aggregate $ 2,000,000 Products/Completed Operations Aggregate $ 2,000,000 Each Occurrence Limit $ 1,000,000 Personal/Advertising Injury $ 1,000,000 Fire Damage (Any One Fire) $ 50,000 Medical Payments (Any One Person) $ 5,000 Coverage to include: • Premises and Operations • Explosions, Collapse and Underground Hazards • Personal / Advertising Injury • Products / Completed Operations • Liability assumed under an Insured Contract (including defense costs assumed under contract) • Independent Contractors • Designated Construction Projects(s) General Aggregate Limit, ISO CG 2503 (1997 Edition or equivalent) • Additional Insured—Owners, Lessees or Contractors Endorsement, ISO Form 2010 (2004 Edition or equivalent) • Additional Insured—Owners, Lessees or Contractors Endorsement, ISO CG 2037 (2004 Edition or equivalent) • The policy shall be endorsed to include the following additional insured language on the Additional Insured Endorsements specified above: "County, its subsidiary, parent, associated and/or affiliated entities, successors, or assigns, its elected officials, trustees, employees, agents, and volunteers named as an additional insured with respect to liability and defense of suits arising out of the activities performed by, or on behalf of the Contractor, including completed operations". F1 Contract # 046-2015 Budget Line Item# 404.25.00000.82000 Rev. 8.3 1.11 jaa/js 2/6/2012 Im 3. Auto Liability: Bodily injury and property damage for any owned, hired, and non - owned vehicles used in the performance of this Contract. Minimum Limits: Bodily Injury/Property Damage (Each Accident) $ 1,000,000 4. Special Coverages (check as appropriate and insert amount): ❑(1) Performance Bond $ ❑ Labor and Material $ ❑ Payment Bond $ ❑(2) Professional Errors and Omissions ❑(3) Aircraft Liability 0(4) Owner's Protective ❑(5) Builder's Risk ❑(6) Boiler and Machinery ❑(7) Loss of Use Insurance ❑(8) Pollution Liability ❑(9) Crime, including Employee Dishonesty Coverage, or Fidelity Bond B. Proof of Insurance: 1. Each insurance policy required by the insurance provisions of this Contract shall provide the required coverage and shall not be suspended, voided or canceled except after thirty (30) days prior written notice has been given to the County, except when cancellation is for non- payment of premium, then ten (10) days prior notice may be given. Such notice shall be sent directly to (County Representative's Name & Address). If the insurance carrier will not provide the required notice, the Consultant/Contractor and or its insurance broker shalt notify the County of any cancellation, or reduction in coverage or limits of any insurance within seven (7) days of receipt of insurers' notification to that effect. Simultaneously with the Certificates of Insurance, the Contractor shall file with the Procurement Officer a certified statement as to claims pending against the required coverages, reserves established on account of such claims, defense costs expended and amounts remaining on policy limits. 2. In addition, these Certificates of Insurance shall contain the following clauses: a. The contractor's insurance shall be primary and non-contributory with any insurance or self insurance purchased by the County. b. The insurance companies issuing the policy or policies hereunder shall have no recourse against the County of Pitkin for payment of any premiums or for assessments under any form of policy. C. Any and all deductibles or self insured retentions in the above-described insur- ance policies shall be assumed by and be for the amount of, and at the sole expense of the Contractor. d. Location of operations shall be: "all operations and locations at which work for the referenced Project is being done." 61 Contract # 046-2015 Budget Line Item# 404.25.00000.82000 Rev. 8.31.11 jaa/js 2/620121m 3. Certificates of Insurance for all renewal policies shall be delivered to the County's Representative at least fifteen (15) days prior to a policy's expiration date except for any policy expiring on the expiration date of this contract or thereafter. 4. The County reserves the right to request and receive a copy of any policy and any policy endorsement at any time during the tern of this contract. 14. Exemptions and Preferences. All purchases of construction or building or any other materials for this contract shall not include Federal Excise Taxes or Colorado State or local sales or use taxes. Pitkin County is exempt from such taxes under registration numbers 98-02624 and 84-78000-5K. 15. Records. The Contractor shall maintain comprehensive, complete and accurate books, records, and documents concerning its performance relating to this contract for a period of three (3) years after final payment under the contract and the County shall have the right within the three (3) year period to inspect and audit these books, records and documents, upon demand, in a reasonable manner and at reasonable times, for the purpose of determining, by accepted accounting and auditing standards, compliance with all provisions of the contract and applicable law. 16. Contract Made in Colorado. The parties agree that this contract was made in accordance with the laws of the State of Colorado and shall be so construed. Vcnue is agreed to be exclusively in the courts of Pitkin County, Colorado. 17. Attorney's Fees. In the event that legal action is necessary to enforce any of the provisions of this contract beyond the arbitration described in Paragraph 9, the substantially prevailing party shall be entitled to its costs and reasonable attorney's fees. 18. Governmental Immunity. Contractor agrees and understands that Pitkin County is relying on and does not waive, by any provision of this contract, the monetary limitations or terms (presently $150,000 per person and $600,000 per occurrence) or any other rights, immunities, and protections provided by the Colorado Governmental Immunity Act, 24-10-101, e/ seq., C.R.S., as from time to time amended, or otherwise available to Pitkin County or any of its officers, agents or employees. Further, nothing in this contract shall be construed or interpreted to require or provide for indemnification of the Contractor by the County for any injury to any person or any property damage whatsoever which is caused by the negligence or other misconduct of the County or its agent or employees. 19. Current Year Obligations. The parties acknowledge and agree that any payments provided for hereunder or requirements for future appropriations shall constitute only currently budgeted expenditures of Pitkin County. Pitkin County's obligations under this contract are subject to Pitkin County's annual right to budget and appropriate the sums necessary to provide the services set forth herein. No provisions of the contract shall constitute a mandatory charge or requirement in any ensuing fiscal year beyond the then current fiscal year of Pitkin County. No provision of the contract shall be construed or interpreted as creating a multiple -fiscal year direct or indirect debt or other financial obligation of Pitkin County within the meaning of any constitutional or statutory debt limitation. This contract shall not directly or indirectly obligate Pitkin County to make any payments beyond those appropriated for Pitkin County's then current fiscal year. No provisions of this contract shall be construed to pledge or create a lien on any class or source of Pitkin County's moneys, nor shall any provision of this contract restrict the future issuance of Pitkin County's bonds or any obligations payable from any class or source of Pitkin County's money. M Contract # 046-2015 Budget Lute Item# 404.25.00000.82000 Rev. 8.3 1.11 jaa/js 2/6/2012 Im 20. Notice. Any written notice required by this contract shall be deemed delivered through any of the following: (1) hand delivery to the person at the address below; (2) delivery by facsimile with confirmation of receipt to the fax number below; or (3) within three (3) days of being sent certified first class mail, postage prepaid, return receipt requested addressed as follows: A. To Pitkin County Dustin Havel 0233 East Airport Rd. Aspen, Colorado 81611 Fax: 970-429-1892 B. To Contractor: Vaisala Inc. 194 South Taylor Avenue Louisville, CO 80027 with copies to: Pitkin County Attorney's Office 530 E. Main Street, #302 Aspen, Colorado 81611 Fax: (970) 920-5198 21. Public Contracts for Services and Public Contracts with Natural Persons. In conformance with the provisions of C.R.S. § 8-17.5-101 and 102, as amended and C.R.S. § 24-76.5-101, as amended PUBLIC CONTRACTS FOR SERVICES. CRS §8-17.5-101. [Not Applicable to agreements relating to the offer, issuance, or sale of securities, investment advisory services or fund management services, sponsored projects, intergovernmental agreements, or information technology services or products and services] Contractor certifies, warrants, and agrees that it does not knowingly employ or contract with an illegal alien who will perforin work under this contract and will confirm the employment eligibility of all employees who are newly hired for employment in the United States to perform work under this contract, through participation in the E -Verify Program or the Department program established pursuant to CRS §8-17.5-102(5)(c), Contractor shall not knowingly employ or contract with an illegal alien to perform work under this contract or enter into a contract with a subcontractor that fails to certify to Contractor that the subcontractor shall not knowingly employ or contract with an illegal alien to perform work under this contract. Contractor (a) shall not use E -Verify Program or Department program procedures to undertake pre-employment screening ofjob applicants while this contract is being performed, (b) shall notify the subcontractor and the contracting State agency within three days if Contractor has actual knowledge that a subcontractor is employing or contracting with an illegal alien for work under this contract, (c) shall terminate the subcontract if a subcontractor does not stop employing or contracting with the illegal alien within three days of receiving the notice, and (d) shall comply with reasonable requests made in the course of an investigation, undertaken pursuant to CRS §8-17.5-102(5), by the Colorado Department of Labor and Employment. If Contractor participates in the Department program, Contractor shall deliver to the contracting State agency, Institution of Higher Education or political subdivision a written, notarized affirmation, affirming that Contractor has examined the legal work status of such employee, and shall comply with all of the other requirements of the Department program. If Contractor fails to comply with any requirement of this provision or CRS §8-17.5-101 et seq., the contracting State agency, institution of higher education or political subdivision may terminate this contract for breach and, if so terminated, Contractor shall be liable for damages. PUBLIC CONTRACTS WITH NATURAL, PERSONS. CRS §24-76.5-101. Contractor, if a natural person eighteen (18) years of age or older, hereby swears and affirms under penalty of perjury that he or 7 Contract # 046-2015 Rev. 8.31.1 I jaatjs Budget Line Item# 404.25.00000.82000 216/2012 Im she (a) is a citizen or otherwise lawfully present in the United States pursuant to federal law, (b) shall comply with the provisions of CRS §24-76.5-101 et seq., and (c) has produced one form of identification required by CRS §24-76.5-103 prior to the effective date of this contract. Addendum. Force Maieure. Neither par ly shall be deemed to have breached the Agreement by reason of delay or failure in performance resulting from causes beyond the control, and without the fault or negligence, of the party. Such causes include, bill may not be limited to, an act of cod, an act of war or public enemy, riot, epidemic, fire, flood, quarantine, embargo, epidemic, unusually severe heather or other disaster, or compliance with laws, governmental acts or regulations, in any case, not in effect as of the date of the Agreement, or other causes similar to the foregoing beyond the reasonable control of the parry so affected. The party seeking to avail itself of any of the foregoing excuses must promptly notify the other party of the reasons for the failure or delay in connection with the performance hereunder and shall exert its best efforts to avoid further failure or delay. However, the Agreement shall terminate, as provided under Section 6, if such delay or failure persists for one -hundred twenty (120) consecutive days and there is no foreseeable remedy or cure available. No Special DamaYes. Neither party shall be liable for losses or damages which are special or exemplary arising form or related to this agreement. IN WITNESS WHEREOF, the parties have executed this contract as of the date first set out herein above. CONTRACTOR: Title eo4Pox-r)E 746 /rr Date PITKIN COUNTY, COLORADO: By:J�l 2 7— 7— 0IS Dustin Havel, Assistant Aviation Director—/Operations & Facilities Date BY�— `Jon Perck, C ty Manager IF A STANDARD ONAL LANGUAGE ADDED: John Ely tnt orney Date Contract # 046-2015 Rev. 8.31.1 1 jaa/js Budget Line Item# 404.25.00000.82000 2/6/20121m she (a) is a citizen or otherwise lawfully present in the United States pursuant to federal law, (b) shall comply with the provisions of CRS §24-76.5-101 et seq., and (c) has produced one form of identification required by CRS §24-76.5-103 prior to the effective date of this contract. Addendum. Force Ma'e� ure. Neither parry shall be deemed to have breached the Agreement by reason of delay or ,failure in performance resulting from causes beyond the control, and without the fault or negligence, of the party. Such causes include, but may not be limited to, an act of God, an act of war or public enemy, riot, epidemic, fire, flood, quarantine, embargo, epidemic, unusually severe weather or other disaster, or compliance with laws, governmental acts or regulations, in any case, not in effect as of the date of the Agreement, or other causes similar to the.foregoing beyond the reasonable control of the party so affected. The party seeking to avail itself of any of the foregoing excuses must promptly notify the other party of the reasons.for the,failure or delay in connection with the performance hereunder and shall exert its best efforts to avoid further failure or delay. However, the Agreement shall terminate, as provided under Section 6, if such delay orfailure persists.for one -hundred twenty (120) consecutive days and there is no foreseeable remedy or cure available. No Special Damages. Neither parry shall be liable for losses or damages which are special or exemplary arising form or related to this agreement. IN WITNESS WHEREOF, the parties have executed this contract as of the date first set out herein above. CONTRACTOR: By: V 'r'M6 nivy 4T- ma4*, Title eo+tltrtLli'E SEzATmeY 2-12o/lc Date PITKiN COUNTY, COLORADO: 0 Dustin Havel, Assistant Aviation Director—Operations & Facilities Date Jon Peacock, County Manager IF A NON- STANDARD/ADDITIONAL LANGUAGE ADDED: John Ely, County Attorney Date Contract # 046-2015 Rev. 8.31.11 jaa/js Budget Line Item# 404.25.00000.82000 2/6!2012 Im Exhibit A VAISALA 194 tiouth Turlur Aw. LauL.VW. CO 80031 AVIATION SUPPORT AND MAINTENANCE SERVICES Order and Pricing Schedule Vaisala: Customer: Pitkin County Vaisala Inc. Aspen -Pitkin Comity Airport 194 South Taylor Ave. 506 B Main Louisville, CO 80027 1 Aspen, CO 81611 This Order and Pricing Schedule is incorporated by reference into the Agreement for Aviation Support and Maintenance Services between the panics, and the Statement of Work, and made a part thereof. The Effective Date of this Agreement is 01 April , 2O IS The Term of this Agreement shall he for a period of 1 year(s) from the Effective Date. Services (checkasapplicable) ❑O Preventive Maintenance O Equipment Restoration 3/Year I'ans Included ❑ Data Service Equipment (check as Manufacturer/Model Equipment (check as ManufaclurerINfodel applicable) applicable) ❑ VOR ❑ RVR ❑ DME ® RWIS ❑ LOC ❑ NDB ❑ GS ❑ Control Tower ❑ AWOS ❑ Markers ❑ TWX/LTS ❑ Other Data Services (check as applicable) 1.500.00 ❑ AviMet Data Link Holiday Feb ❑ Navigator n 500.00 ❑ OLD 360 - Service Size: Cancellation/Delay Fee ❑ NLDN Stroke Data - Service Size: 500.00 ❑ CL.DN Stroke Data - Service Size: ❑ AviCast ❑ AviCasl Lightning Warning System Fees I Contract Total: S 8.050.00 Annual Fee $ 8,(150.(10 billed Annually Unplanned Outage Fee $ 1,500.00 per day (es. lightning strike, bird strike) Facility Visit Fee $ 1.500.00 per (]try (ex. flight check) Holiday Feb $ 500.00 per da • additional Cancellation/Delay Fee $ 500.00 per day Maintenance Agreement Page I of 2 Contract # 046-2015 Budget Line ]tern# 404.25.00000.82000 Statement of Work and Additional Terms Attachment I - Tens & Conditions Attachment 2 - RWIS Statement of Work Rev. 8.31.11 jaa/js 2/6/2012 Im Invoice Contact: Airport Manager/Authority: Pitkin County P Name; Dustin Navel Name: 5061: Main 0233 C Airport Road Address: Aspcn. CO 81611 Address: Aspen, CO 8161 1 9709205200 Phone: Phone: 970 429 2855 Email' Finail: dustin.havcl((i;aspcnairpan.eom Accepted and agreed to by the duly authorized signatories below. Vaisala Inc. Pitkin County JD Kirkpatrick BY: By: Sales Manager Sales Title: Date: Date: Maintenance Agreement Page 2 of 2 Me Contract # 046-2015 Budget Line Item# 404.25.00000.82000 1 � , 194 South Toytor Ave. Loukvitle, CO M0027 Attachment 2 RWIS Maintenance Statement of Work Description of Equipment Ser•icts. Rev. 8.3 1.11 jaa/js 2/6/20121m LL Preventive Maintenance consists of inspection, functional checks, adjustments, replacement of failed components and cleaning in accordance with the equipment manufacturer's published guidelines and requirements. Vaisala will perform one (1) preventive Maintenance check per year at Custmner's site and notifv customer at least one week in advance of the estimated service time. Vaisula shall make a report in writing containing observations and actions taken during each Maintenance visit and a copy will he supplied to Customer. 1.2. Fquipment Restoration. In the event of an unplanned equipment failure or oulage. vaisala Shall commence restortion %%ark within two (2) business days after the outage is reported and complete restoration services in a reasonable prompt manner. Diagnosis may he pe'rfonned remotely and render the system inoperable until which time replacement equlpt eni/pans can arrive in Customer's site. Repairs required due to Acts of God, lightning, vandalism, etc, are excluded and will he billed at the Unplanned Outage price. A maximum of three (3) restorative trips per year are allowed under contract. If more trips tare required the unplanned outage fee will apply. 1.3. All services provided by Vaisala shall be perfornncd by qualified field technicians and other person el having all required certifications and licenses required. 2. Replacement Paris. 2.1. I'aventent Sensors that require replacement for reasons other than electronic failure (consmrction. rubber Intild-up, etc) are billed and installed at list price. Saw cutting of pavement far replaced sensors is in the expense of customer. 2.2. Sensor failures including the system, and RI,U which occur during the course of this contract, are covered including pans and labor. Vaisala may replace sensors, parts or equipment with factory reconditioned units. "nils does not include island server systems and equipment that is no longer manufactured or supported by Vaisala. 2.3. Sensor replacement requires appropriate weather conditions. Vaisala will not replace sensors when appmpriamc weather conditions du no exist. Replacement of sensors is contingent tun Customer providing Vaisala access to the sensors and managing airport operations accordingly. 3. Customer Responsibilities. 3.1. Customer shall be responsible for monitoring the sums of the systems following maintenance by Vaisala if customer has their own serer. 3.2. Customer sliall be responsible for providing transportation andaor access for Vaisala personnel between the airport terminal and the location of the Equipment: 3.3. Customer shall be responsible for providing security in and around the Equipment to be maintained under the Agreement - 3.4. Customer shall l c responsible for any loss or damage to the Equipment for reasons other than the fault of Vaisala and for providing any insurance Customer may desire to cover any such loss ortlannpge.: 3.5. Customer shall be responsible for maintaining the grounds and buildings associalcd with Equipment in goad repair. 11