The URL can be used to link to this page

Home My WebLink Aboutbocc.con.amended.060.2014Q 7/2015 kjm fiorKIN Pitkin County CouNT1/ Contract Cover Sheet Please complete the Contract Cover Sheet when the contract is completed and signed by Contractor and Pitkin County Project Manager. Return all Contract Cover Sheets and Contracts/Change Orders/Amendments to Procurement (procurement_help@pitkincounty.com).Any contracts$50,000 and over will be routed for signatures to County Manager and Attorney's Office(if required)by Procurement&Contracts Manager. Contract Information Contract Number 60.2014Q Project Name Pitkin County Library Expansion Contractor FCI Constructors,Inc. Budget Line Item 116.63.92863.86200 Additional Budget Line Item(s) Click here to enter text. and special notes to Finance Contract Start Date 6/19/2014 Contract End Date 4/28/2016 Automatic Renewal Yes ❑ No►l If Construction: Retainage Click here to enter text. If this is a new contractor,please request they complete and submit to Finance a W-9 Form. Contact Information: Department Facilities Project Manager Smith Project Manager 5396 Phone Provide a brief description of the contract: The Contractor shall execute this Change Order Request based on County revisions. The work includes the refund of cost to repair damage to existing parking garage precast, green roof screen wall, lighting control additions,Unit heater and accordion door. Contract Value Summary: Contract Amount $ 10,508,988.88 This Change order/Amendment amount(if applicable) $ 18,336.00 New Contract Total $ 10,527,324.88 Procurement Method: None ❑ Informal❑ Formal Sole Source ❑ Emergency 0 Contract Renewal 0 Contract Type: Services/Maintenance El Construction ® Goods,Equipment, Supplies ❑ Change Order/Amendment 0 Other,please explain❑ Click here to enter text. NOTE: CLERKS OFFICE WILL KEEP ORIGINAL DOCUMENTS IN COMPLIANCE WITH COLORADO STATE ARCHIVES RETAINAGE SCHEDULE.ALL ATTACHMENTS MUST BE WITH THIS CHECKLIST. Contract 1160.2014 Rev. 8.31.11 jaa js Budget Line Item N 166.63.92863.86200 41'11'1{ 1N CO N 1141 (c. CONTRACT AMENDMENT Change Order Number: 60.2014Q Dated 121015 OWNER: Pitkin County Library 485 Rio Grande Place#101 Aspen,Colorado 81611 CONTRACTOR: FCI Constructors, Inc. The Library Expansion Project CM/GC Contract (the "Agreement") dated 6/19/2014 between the Board of County Commissioners of Pitkin County (the "County") and FCI Constructors, Inc. (the "Contractor"), is hereby amended as follows: Description of Change: a. BVR-005—RFI-113 —North Alley Snowmelt Repair $0.00 b. COR-041 —Cost to Repair Damage to Existing Parking Garage Precast ($5,532.00) c. COR-069-RFI 068—Magnetic PLAM-8 $1,638.00 d. COR-070—RFI-076 Green Roof Screen Wall $16,760.00 e. COR-071 —RFI-089RN—Delete W6 Fixture ($539.00) f. COR-078—Box Walk Lighting Control Additions $1,902.00 g. COR-081 —RFI-110—Unit Heater UH-1 $1,127.00 h. COR-082—PR 23 —Accordion Door 8 Details $2,980.00 TOTAL THIS CHANGE ORDER $18,336.00 Reason for Changes a. Owner Request b. Pay back PC for cost of damage to COA garage by an FCI Sub c. Owner Request d. Design Revision e. Owner Request f. Owner Request g. Design Omission h. Design Revision Page 1 of 2 Rcv 12/27/10 is Project Coding Original Contract# Original Contract Price $4,500,000.00 Previous Change Order applied to Guaranteed Maximum Price: $6,008,988.88 Net Increase in Contract Price(this change order) $18,336.00 *Total Adjusted Contract Price(including this change order) $ 10,527,324.88 This change order extends the time to substantial complete of the work to April 28,2016. In all other respects the Agreement is in full force and effect and remains unchanged by this Amendment. )4--- December 10,2015 Stan Kiser,FCI Constructors Inc Date iiv JSmith,facilities Date Jon Pea ck,County Manager Date "Increases over$25,000 and/or 10%(single increase or accumulative)of original contract must have County Manager signature. 2 FCI BVR-005 Constructors,Inc. Total Change Pitkin County Library Expansion Project# 10-14-023 FCI Constructors, Inc.-GJ 120 North Mill Street,Aspen,CO 81611 Tel: 970-429-1932 Fax: 970-434-7583 11 1 12Gi5 RFI 113-North Alley Snowmelt Repair Released For Construction Category Reference PCCO Number Budget Variance Report RFI 113 Notes This COR is for costs associated with replacing the snowmen in the north alley in the area of sidewalk and pavement that had to be removed for the installation of the new water treatment vault. The new snowmelt will be installed as a separate zone and will be tested independently of the existing snowmelt to the west;5/8"tubing spaced at 9"on center will be placed in in the concrete pavement over 2"of rigid foam, The existing snowmelt will be reconnected by connecting the loops that were cut with new tubing and it will operate as an independent zone. No costs have been included to repair nor can FCI guarantee the functionality of the existing radiant heat systems. Winter conditions for this work will be covered by FCI's existing winter conditions budget. Itemized Details: General Description Quote Rec'd Proposed Aspen Earthmoving $5,800,00 Description of Work: Demo and dispose of additional paving at the north alley for snowmelt tie in. Prep subgrade for new concrete. S2M Construction Company,Inc. ($7,260,00) Description of Work: Credit for 2000 SF of 8'reinforced paving wf 04 at 18"oc each way=($17,000) Add for install 70'of 18"curb,180 sf of sidewalk with mesh, 1 handicap ramp(no truncated domes),and 540 sf of reinforced paving w/#4 at 18"oc each way,640 sf of 2"(25 psi minimum)rigid foam insulation=$9,720 Net credit=$7,280. 2 H Mechanical,LLC $7,215.00 Description of Work: Replace snowmelt in the north alley,test and reinstall as 2 zones:old zone in undisturbed pavement,new zone in newly installed pavement. Includes valve box, all rough in material,5/8"Uponortubing at 9"on center,insulation,valves,glycol, installation, testing and documentation. FCI Constructors, Inc.-GJ $319.00 Description of Work: Fee $0.00 Description of Work: Contingency Requested Days: 0 Total Change to Contract: ($6,054.00) Pete SGftCtl, �ezeititied Sa/e weed€et 11/30/2015 10:2.0:51 AM This proposal includes work clearly itemized herein and attached sub-contractor quotes Should delivery of materials effected by this change delay the work,time extension and General Conditions cost rights are reserved The right to cumulative impact costs is reserved This proposal is good for seven days from date of issuance Prolog Manager Printed on: 11/25/2015 fci pm data Page 1 of 1 \\\ x L_ spit Ty hhirasit4 ASPEN EARTHMOVING lulu,XII(l,lstill/11•I ,(L-.( VtR(1\I,\It, xlr.a PII1I\1: (17011(,(-0177 t 1\ WO) O-::4 Work Order Report Project Name: Pitkin County Library COR-Demo Conc,Slab Customer: FCI Constructors, Inc. Prep Job Number: Bid Number: 214069 Billing Address: 30701-706,Building A, PO Box 1767 Bid As: Grand Junction,CO 81502 Estimator: Phone: 720-552-1072 Project Address: City Of Aspen,Aspen,CO Contact: Gene Temanson Completion Date: Pay Items Description AEM Item# Cost Code Quantity UM ,.. j 13.00-Demo Additional Concrete In Alley 1.00 LS Additional Concrete Slab Prep In Alley Price Includes Concrete Haul Off And Dump Fees �:J Field Supervision -013003 13,00 01.30.03 2.00 DY C, Superintendent 16.00 HR JD Demolition-024001 13.00 02.40.01 300.00 SF kB Crew(300.00 SF/DY,1.00 DY) 300.00 SF 4 L426 Backhoe 8.00 HR Cs Operator 9.00 HR 4 LBKR-Breaker(L426) 8.00 HR Labor 9.00 HR 4 837 Mini Excavator 8.00 HR Operator 9.00 HR AO Trucking(Conc. Haul Off)(0.40 DY, 1.00 Trucks,70.00 TON/DY) 28.00 TON Dump Fee-Dirty Concrete W/Rebar 14.00 TON py Concrete Slab Prep-312013 13.00 31.20.13 300.00 SF Crew(300.00 SF/DY,1.00 DY) 300.00 SF 4 B160 Skid Steer 8.00 HR Cs Operator 9.00 HR 4 C305 Walk Behind Compactor 8.00 HR CS, Labor 9.00 HR 80 Trucking(0.20 DY, 1.00 Trucks, 70.00 TON/DY) 14.00 TON 3/4"Road Base(Class 6) 14.00 TON 11/20/2015 8:40:2S AM 1 Adam Shuler From: Tom Vagell <tom@2hmech.com> Sent: Thursday, October 29, 2015 11:22 AM To: Gene Temanson Cc: Adam Shuler;Jim Conrardy Subject: Pitco Library Snowmelt Guys, Per field meetings and discussions, below is the price for 600 S.F. of snowmelt at the library. We have figured 5/8" Uponor Pex 9"on center as the standard. Price includes rough-in material, pex tubing,glycol, non-traffic rated yard box, and pipe insulation: $7,215.00 Exclusions are: under slab insulation, controls, excavation and backfill, core drilling. Let me know and I will provide a formal COR. Thanks, Tom Tom Vagell, LEED AP BD+C V.P. Plumbing/Piping Division 2H Mechanical LLC 566 S.Westgate Dr. Grand Junction, CO 81505 Office: 970.778.4560 Cell: 970.433.2417 Fax: 866.298.6054 e-mail: tom(c�2hmech.com web:www.2hmech.com 1 PCL June 24, 2015 Craig Roth Rider Levett Bucknall 1675 Larimer Street, Suite 470 Denver,CO 80202 SUBJECT: Galena Plaza CRX 024—Concrete Restoration at FCI's Plaza Lid Dear Craig, Subject line Change Order Request stems from changes issued in Desman's Field Observation Report#1 (dated 04/28/15)and Report#3(dated 06/18/15). These include the following: • Two flange hole repairs and a partial depth repair at an area 5' x 5'. This is noted in Desman's report ill. • Partial depth repair at North edge of slab opening,area is approximately 10"x 60',along with five tee-to-tee repairs. Scope assumes existing wire mesh remains in place. If dowels are required,cost will be assessed following direction provided by the structural engineer. If you have any questions or concerns; please do not hesitate to contact me. Sincerely, 9/-1 Kerri Shephard File:2A.1 A Kerri Shephard Subject: FW: galena plaza update Attachments: inv tee east D-6.JPG; inv tee west D-6.JPG; tee flange Grid G south of 4.JPG;flange hole.JPG; flange hole2.JPG; pock marks at C-4 topside.JPG From: Bruce Collins [mailto:bruce@restruction.com] Sent:Tuesday,June 16,2015 10:35 AM To: Eric Gradyan; Kerri Shephard Cc:'Gtemanson@fciol.com';Josh Sterrett;Jesse Davis;Sam Armour;Bruce Collins Subject:galena plaza update Hello all here is where we stand on galena plaza concrete repairs 1. Restruction completed mobilization last week. For contract purposes mob fee=$12,020.00 2. By the end of this week Restruction will have completed 17 floor drain repairs. For contract purposes billing will be 17 each x$1758.10 per each = $29,887.70 similar to detail 1 sheet SR3.01 3. We expect to complete by end of week two inverted tee repairs, no shoring, immediately east and west of gridlines D-6. For contract purposes,2 each x$1000.00 per each=$2000.00 No corresponding detail 4. We expect to complete by end of week, 1 tee flange repair,located south of gridline 4 at gridline G.This is best accomplished as a full depth repair similar to drain detail. For contract purposes 1 each x$1758.10=$1758.10 See picture attached.Similar to detail 1 sheet SR3.01 5. We expect to complete 2 flange hole repairs,This is best accomplished again with full depth repair similar to drain repair. See pictures attached, For contract purposes expect 2 each x$1758.10 per each=$3516.20 similar to detail 1 sheet SR3.01 6. Next week we intend to repair a 5' xS'area of pock marks. location Is topside of grids C-4.This will be done by scarifying the entire area to a depth of approximately 3"and floating in the sika 611 material. For contract purposes$1,200.00. No similar detail provided. 7. Next week we intend to repair, however, need approval of submitted procedure, 11 dapped stem locations, no shoring.Cost to be sent upon method approval or scope clarification, RFI submitted. So currently we have a contract expected amount of$50,382.00 plus cost of tee end repairs.The current contract is set at$41,974.00 I have received no other notifications of extension. Please provide extension prior to end of week.Thank you Regards Bruce A.Collins Business Development #303-619-0041 http://www.restruction.com/ Follow me and Restruction @ OD es 'S. .! • r'h • • • :fes. f.' �•t: fj. fzy' s, c *t' • ^y. Z: 7Y Y�;,a' a. n' - Y. ... r♦ - :Y.. _ -n a •.c ,. of.. ..'.. •.. .� - ti yt ., b c w ♦" w m .. .. ♦ - �. r • ,� tir i t . JP. _ .:` Y � ey '^ � . , • _.- 'Y - I y a- Y:.: - 4.010041W iC I Request for Information 068r1 Constructors,Inc. Detailed,RFIs Grouped by RFI Number Pitkin County Library Expansion Project# 10-14-023 FCI Constructors,Inc.-GJ 120 North Mill Street,Aspen, CO 81611 Tel: 970-429-1932 Fax: 970-434-7583 RFI#: 068r1 Date Created: 9/1/2015 Answer Company Answered By Author Company Authored By Snowdon and Hopkins Architects, Leah Mayer FCI Constructors, Inc.- GJ Adam Shuler PC P.0. Box 3340 P. 0.Box 1767 Vail, CO 81658 Grand Junction,CO 81502 Co-Respondent Author RFI Number Subject Discipline Category PLAM-8 Magnetic or Not Architectural Request for Information Cc: Company Name Contact Name Copies Notes FCI Constructors,Inc.-GJ Tim Thornell 1 FCI Constructors, Inc.-Longmont Gene Temanson 1 Wilkie Sanderson Justin Weller 1 Question Date Required: 9/8/2015 The sample that Pitkin County Library had from the design phase for the marker board material was noted as magnetic. The schedule from MSR does not indicate magnetic PLAM-8 material. Does PLAM-8 need to be magnetic? Suggestion Answer Date Answered: 10/15/2015 [10/15/2015 Snowdon and Hopkins Architects, PC-Leah Mayer] Provide Richwood magnetic dry-erase High Pressure laminate, if is in stock.' liwimighwoodind.com/dry-vr i ncategorisedr52-magdryerasehpi43.himl; If this product is not in stock,use the#150 Chemetal backer http://www.chemetal.com/designs/custom-magnetic-it is.05" as a backer on the Richmond dry-erase laminate as originally specified. This discussion and decision was made at the OAC meeting on 10/14/15. An additional cost will be incurred to add the magnetic backer. It is estimated to be in the$2,000 range. Leah Mayer 10/15/15 If costs result from changes within this RFI answer notify FCI within 5 business days. Prolog Manager Printed on: 10/23/2015 fci pm data Page 1 of 1 Adam Shuler From: Justin Weller <justin.weller@wilkiesanderson.com> Sent: Thursday, November 19, 2015 2:13 PM To: Adam Shuler Subject: RE: PCL RN: RFI 068 - PLAM-8 Magnetic or Not.pdf Adam, The angle that they have specified per RFI 080RN will not work. See Snipit below. Overall length of angle is 3/4" minus the 3/32"wall thickness leaving only 21/32" inside leg dimension. Overall panel thickness will be closer to 13/16"or 7/8" by the time we have the richwood laminate on the face and a balanced backer sheet on the back side of the 11/16" panel. I would propose that we use an angle 1 size larger at 1/2"x 1"x 3/32" wall thickness. 3/8" 3/32" --r- 3/4"3/4" The below is the proposed 1 • F,. ! CI COR-070 Constructors,Inc. Detailed,Grouped by Each Number Pitkin County Library Expansion Project# 10-14-023 FCI Constructors,Inc.-GJ 120 North Mill Street,Aspen,CO 81611 Tel: 970-429-1932 Fax: 970-434-7583 1013012016 RFI 076 Green Roof Screen Watt Pending Approval Category Reference PCCO Number Change Order Request RFI 076 Notes This COR if for costs associated with RFI 076 for changes to the screen wall for the water treatment system at the green roof. Included in this COR are structural steel support,metal siding changes,additional cementitious siding. Note that the structure is to be painted with a high performance paint in lieu of hot dip galvinizing. Also,cementitious siding has been added to the interior of the screen wall assembly to protect sheathing from exposure; this will be painted. Itemized Details: General Description Quote Rec'd Proposed FCI Constructors,Inc.-GJ $9,875.00 Description of Work: Provide structural steel frame per RFI 076 GZO Sheet Metal&Roofing,Inc. 86,185.00 Description of Work: Furnish and instal z furring,insulation,and additional cap material for screen wall per RFI 076 to be neatly integrated into metal wall panels on building. Modify roof waterproofing as required to flash in structure. Peak Interiors,Inc. $958.00 Description of Work: Furnish and install framing between structural steel framing and wall framing,provide exterior gyp for screen well per RFI 076. Innovative Painting Systems,Inc. $925.00 Description of Work Paint steel structure with Tnemec paint and paint cementitious siding with high performance exterior paint as recommended by manufacturer. FCI Constructors,Inc.-GJ $2,070.00 Description of Work: FCI self perform cement board installation and assist in material placement for structure. 40 hrs x$36/hr=$1,440 Material=$630 FCI Constructors,Inc.-GJ $248.00 Description of Work: Self perform fee. FCI Constructors,Inc.-GJ ($4,872.00) Description of Work: Credit forodgiral structure. FCI Constructors,Inc.-GJ_ _ $24.00 Description of Work: Builders Risk Insurance FCI Constructors,Inc.-GJ $.81.00 Description of Work: General Liability FCI Constructors,Inc.-GJ $138.00 Description of Work: Payment/Performance Bond FCI Constructors,Inc.-GJ $1,128.00 — This proposal includes work dearly itemized herein and attached sub-contractor quotes Should delivery of materials effected by this change delay the work,time extension and General Conditions cost rights are reserved The right to cumulative impact costs is reserved This proposal is good for seven days from date of issuance Prolog Manager Printed on: 11/11/2015 fci pm data Page 1 of 2 Adam Shuler From: Gorden Cole <gcole@wsiron.com> Sent: Wednesday,October 14, 2015 6:34 PM To: Stan Kiser; Gene Temanson Cc: Adam Shuler Subject: RE:PCL RFI 076.pdf Attachments: 125694-3DPDF.PDF; E1-r0.pdf; 1001-r0.pdf; 1002-r0.pdf Stan, The cost to supply and install the Storm Water Screen Frame for the Pitkin County Library is as follows. For the sum of $9,875.00 Including the following: • Shop& Erection Drawings(See attached) • All Steel Material and Erection Bolts • Fabrication Labor, fabricated as knocked down assembly to assist with placement of material on roof. • One Shop coat Tnemec 90-97 Zinc Rich Primer in lieu of Galvanizing. • Delivery to Site • All equipment&labor to install per project plans. We are hoping to deliver and install this early next week Tuesday or Wednesday if possible. We will confirm by Friday! Please let me know if you have any questions. Sincerely, Gorden Cole,Vice President Western Slope Iron&Supply, Inc. 670 23 Road Grand Junction, CO 81505 PH (970) 243-9770 Fax (970)241-9770 Cell (970)201-2510 gcole(&.wsiron.com www.wsiron.com From: Gorden Cole[mailto:gcole@wsiron.com] Sent: Monday, October 12, 2015 10:28 AM To: 'Gene Temanson' Cc: 'Stan Kiser'; 'Adam Shuler' Subject: RE: PCL RFI 076.pdf Gene, 1 Scope of Work To include: RFI-076 Storm Water Discharge Basin • Fabricate and install horizontal Z to receive Pure Free Form panels at outer side of screen walls. • Furnish and install wall insulation outer wall of screen wall. • Fabricate and install Pure Free Form, parapet cap and associated flashing at outer screen wall. • Furnish and install associated water proofing flashings, per manufacture detail and specifications. 20% Mark-up $ 620.00 Materials Total $3,100.00 Labor, 29 man hours @ $85.00ea $2,465.00 Base Bid: $6,185.00 Clarifications: No engineer calculation pricing where added to the RFI-076 quote, if in need an additional charge will be submitted. Penetrations need to be coordinated properly for a proper assembly. Exclusions: Carpentry work, masonry work,structural,electrical, exterior painting, permit and permit fees, liquidated damages and consequential damages. All changes to be handle on a time and material basis, hourly rate is$85.00 a man hour. We appreciate the opportunity to quote you on the project above, please let us know of any questions you might have. Tony Sarabia Project Manager/Estimator C 970 319 0923 O 970 920 7697 F 970 920 7090 P.O. Box 1475 Aspen, CO 81612 Gro3@comcast.net IF'S INNOVATIVE Job Number: 15-190 PAINTING SYSTEMS, INC Customer Name:_FCI 898 Highway 133 Job Location: PCL RFI-076 Suite 403 Carbondale CO,81623 Change Order We hereby agree to making the change(s)specified below: Description of Work Changes Labor Cost Material Cost Total Initials 1. Paint the Storm water discharge protector with a HPP. $ 325.00 $ 225.00 $ 550.00 2. $ $ $ 3. $ $ $ 4. $ $ $ NOTE This change order becomes part of and in conformance with the existing contract. Total Change Amount WE AGREE to make the change(s)specified above at this price > $ 550.00 I.Date: 10/15/15—_� Auihei mol s lahne(Contractor) ACCEPTED-The above price and specifications of this Change Order are satisfactory and are hereby Date of Acceptance accepted. All work to be performed under the same terms and conditions as specified in the original contract unless otherwise stipulated. Signature (Owner/Manager) • F C I COR-071 Constructors,Inc. Detailed,Grouped by Each Number Pitkin County Library Expansion Project# 10-14-023 FCI Constructors,Inc.-GJ 120 North Mill Street,Aspen,CO 81611 Tel: 970-429-1932 Fax: 970-434-7583 1013012015 RFI 89RN Delete W6 Fixture Pending Approval Category Reference PCCO Number Change Order Request RFI 089RN Notes - s.x h ., t . . This COR if for costs associated with RFI 089RN to delete the(2)W6 light fixtures from the scope of work. These fixtures were shown outside the main(southwest)entrance to the library. Itemized Details: General Description Quote Rec'd Proposed R 8 A Enterprises ($532.00) Description of Work: Delete W6 fixtures from the scope of work. FCI Constructors,Inc.-GJ ($1•00) Description of Work: Builder's Risk Insurance FCI Constructors,Inc.-GJ ($2.00) Description of Work: General Liability FCI Constructors,Inc.-GJ (:4.00) Description of Work: Paym Bond Requested Days: 0 Total Change: ($539.00) Approval: Date: This proposal includes work clearly itemized herein and attached sub-contractor quotes Should delivery of materials effected by this change delay the work,time extension and General Conditions cost rights are reserved The right to cumulative impact costs is reserved This proposal is good for seven days from date of Issuance Prolog Manager Printed on- 11/13/2015 fci pm data Page 1 of 1 F I - COR-078 Constructors,Inc. Detailed, Grouped by Each Number Pitkin County Library Expansion Project# 10-14-023 FCI Constructors,Inc.-GJ 120 North Mill Street,Aspen.CO 81611 Tel: 970-429-1932 Fax: 970-434-7583 11/17/2016 Box Walk 4,ighting Cock ,Additions Pending Approval Category Reference PCCO Number Change Order Request Box walk narrative, Notes This COR is for costs associated with the addition of 3 new lighting control switches per the box walk notes attached. Rough-in has been installed per the direction given in the walk. Itemized Details: General Description Quote Recd Proposed R&A Enterprises $1,782.00 Description of Work: Furnish and install(3)additional nPODM's pal)tight controllers as noted during the box walk through. Locations as coordinated per field walk. FCI Constructors,Inc.-GJ $2.00 Description of Work Builder's Risk Insurance FCI Constructors,Inc.-GJ $7.00 Description of Work: General Liability FCI Constructors,Inc.-GJ $12.00 Description of Work: Payment/Performance Bond FCI Constructors,Inc.-GJ $99.00 Description of Work: Fee Requested Days: 0 Total Change: $1,902.00 Approval: Date: This proposal includes work clearly itemized herein and attached sub-contractor quotes Should delivery of materials effected by this change delay the work,time extension and General Conditions cost rights are reserved The right to cumulative impact costs is reserved This proposal is good for seven days from date of issuance Prolog Manager Printed on: 11/17/2015 fel pm data Page 1 of 1 I H-'i,t 1 5317 County Rd 154 Ste 201 ��' `' Glenwood Springs,CO 81601 970-945-6500(F)970-945-0500 TNTERPRI S ES OF L:AWUUNUALL. !NU. November 9, 2015 FCI Constructors, Inc. Grand Junction, CO 81504 Re: Pitkin County Library Renovation — R&A CO #17/ Lighting Control Adds in the Expansion per walk through. Included: • Lighting Control Material, (3)NPOMD-2L-WH, $1,232.00 • Lighting Control Labor $550.00 TOTAL Change Order Amount $1,782.00 Please call or e-mail if you have any questions or concerns. Thank you, Kevin Broadhurst R&A Enterprises Pitkin County Library Expansion • OVERVIEW nlight Preset Scene Control WallPods provide users a quick way to set the light levels of an " ACU/i]/Contr01S nLight controlled zone.All nPODM xL devices are single gang wall devices with soft-click push- buttons and green LED indicators for each button.These buttons are field replaceable and can be custom engraved.Two RJ-45 connectors allow the devices to be daisy-chain wired with CATSe nLight cabling to other Might network devices. FEATURES • Sets lights to one of two or four preset levels with single button push pODM 4L DX • Functions as an On/Off switch • Communicates with nLight network nPODM 2L • Remotely Configurable/Upgradable • Softclick push buttons nPDOM 2L AB • Green LED indicator per button • Custom button engraving at No Charge SPECIFICATIONS Size: (not including ground strap)2.74"H x 1.68"W x 1.63"D(6.96 cm x 4.27 cm x 4.14 cm) Weight: 2 oz Mounting: Single Gang Switch Box or low Voltage Ring Color: White,Ivory,U.Almond,Gray nLight Network Ports: 2 RJ-45 'I,, Power Consumption: <5 mA ) Wires: None • ( I„ Operating Temp: 14°to 160°F(-10°to 71°C) Relative Humidity: 20 to 75%non-condensing ROHS compliant Warranty Five-year limited warranty.Complete warranty terms located at: www.acuitybrands.com/CustomerResources/Ferms and conditions.asp.x Note:Actual performance may differ as a result of end-user environment and application. Specifications subject to change without notice. ORDERING INFORMATION • nPODM • Example:nPODM 2L WH ; • Series Preset Type Color Temp/Humidity nPODM 2L Two levels WH White [blank] Normal 2L AB High/low step control IV Ivory LT Low temp 4L DX Four levels with raise/ AL Light almond lower CUSTOM BUTTON ENGRAVING • Standard button labeling is shown on back. • Custom lettering for WH,IV,AL,and GY units can be specified and ordered at no charge at:http://nlightcontrols.com/wp-contentkploads/nGrave_Order_Form.pdf. • To ensure color uniformity,ordering templates facilitate specifiying all buttons on a unit as custom lettered.Replacing single buttons not recommended. • Buttons may ship separately and require held installation. Acuity Brands I One lithonia Way Conyers,GA 30012 Phone:800.535.2465 www.acuitycontrots.com° p 2014-2015 Acuity Brands Lighting,Inc.All rights reserved. 04115115 1 of 2 F C I COR-081 Constructors,Inc. Detailed, Grouped by Each Number Pitkin County Library Expansion Project S 10-14-023 FCI Constructors,Inc. -GJ 120 North kW Street,Aspen,CO 81611 Tel: 970-429-1932 Fax: 970-434-7583 1112612015 RFI 110•Specifications for Unit Heater UH 1.1 Category Reference PCCO Number Change Order Request RFI 110,attached pricing Notes This COR Is for costs associated with providing unit heater UH 1-1 as defined in RFI 110. Itemized Details: General Description � fi ,-n rvz . ' " '?l"o? s. Quote Recd 'i Proposed 2 H Mechanical,LLC $1,056.00 Description of Work: Furnish and install unit heater UH 1-1 as defined by RFI 110. FCI Constructors,Inc.-GJ $1,00 Description of Work: Builder's Risk Insurance FCI Constructors,Inc.-GJ Description of Work: General Liability FCI Constructors,Inc.-GJ $7.00 Description of Work: PaymeuYPMormance Bond FCI Constructors,Inc.-GJ i58,00 Description of Work: Fee Requested Days: 0 Total Change: $1,127.00 Approval: Date: This proposal includes work clearly itemized herein and attached sub-contractor quotes Should delivery of materials effected by this change delay the work,time extension and General Conditions cost rights are reserved The right to cumulative impact costs is reserved This proposal is good for seven days from date of issuance Prolog Manager Printed on' 11/25/2015 fci pm data Page 1 of 1 ri.... CHANGE ORDER REQUEST"565 S.Westgate Iknc F-- " irt O,At815054.••••••; JOB NAME ---^ le(910)778 MO Pain County Library Addition_, t•da(866)798 6054 ,:1n r• t �.• , s.._ __. CUSTOMER --- E�'la ik±: dL� lf_x":�,:1,r,'"•:.." _ FClConstnKtws,Inc y_- ISSUED TO: _........._.. i -DATE __._._.CHANGE ORDER lt,._._.. —.—_ i I112sl2G15 68129-COR-18__'CUSTOMER REFERENCE - 'FCI Constructors,Inc - RFI-110 __ CHANGE ORDER TITLE ____, _____Storage Room U11-1 ___ O�.yi.RIPIION 5UUCUf IRACI t.IArIRIM HOUR', ,AMR f,tw' PIi.1MRING HVAC. 2.00 S Iill(o ( 4 • S 1.0557; i1 rias 3I KW Milk NI $ 925.75 _..._. .._. _._._. j r I .--- .:1.. -.1, [ . • —•—-— _ { ..• 1 • .ii . • 7 . • [ • -1 I t • 1 . I -i • st erorai. sn.no S0.00 SLUK.7S DESCRIPTION of WORK COMPLETED: Provide and Insult 1 Electric Unit Heater UH-1 per specifications provided by ME Engineers Cthe: on REI-110 Unit heater was not scheduled on CD's .�... Total before bond I,055.75, CHANGE ORDER TOTAL 1 S -,.. 1.059U CUSTOMER APPROVAL SIGNATURE PRINT NAME i CUSTOMER COMM0NTS_--_... . __ _ Snowdon and Hopkins Architects,P.C. PROPOSAL PR No. 23 P.O.BOX 3340 REQUEST Vail,Colorado 81658 Date: 11-19-15 (970)476-2201 PROJECT: Pitkin County Expansion ARCHITECT'S PROJECT NUMBER: 1307 120 North Mill street Aspen,Colorado OWNER: Pitkin County CONTRACT FOR: General Construction (Library Expansion) TO FCI Constructors Inc. P.O. Box 1767 Grand Junction,CO CONTRACT DATED:N/A 81502 Please submit an itemized quotation for changes in the Contract Sum and/or Time incidental to proposed modifications to the Contract Documents described herein. THIS IS NOT A CHANGE ORDER NOR A DIRECTION TO PROCEED WITH THE WORK DESCRIBED HEREIN. THE WORK: Revise Door 8 to be an accordion door. Specifications per drawing AX-17. Revise door trim @ Door 8& Door 19 to be trimless per details on drawing AX-17. Contractor to provide pricing for both clear anodized and bronze finish for Owner's review ATTACHMENTS: EX:AX-17, dated 11-9-15 Manufacturer brochure&installation detail sheets Copy To:Jodi Smith and Dave Detwiler ARCHITECT: CONTRACTOR: Snowdon and Hopkins Architects,P.C. FCI Constructors inc. BY: Leah Mayer I ' Woodfold Door Series 640 & 740 Alumifold security doors. A sturdy door that incorporates ' , ._ the smooth operation of our exclusive _ r hardware hinge system the Scrics 640 --- , 1 It1:44-,;.i.,; ',3,;;,7';:::,' and 740 feature single-piece, extruded ,'- 11. 1 ' ,` aluminum body panels.Suitable for :IN 1 1 f , •, r, a variety of installations that require '" ,`: t ;: z5 and 1 G If i C;1411ign options like ;' , �( .4 I' solid or perforated aluminum, in t ' bronze,gold or clear (silver) finishes i • 11', for a streamlined, modern look. + 9 kt®� t I ' tf, For construction details please see page 12. 11 { ( Ir ,'111 lilt, 11111 jf w !" 11111 I I 11 t11 1111 s 3� .�., ✓J ilf : IIi111 1'1i i 1 s � �,� 111 ..11,11 1111 1� : . , ) 111 1141 1111 111 1.111 1111 III 11111 I i l 111 Hill 111: 11 1 II 1 . .' !II 11111 illi , i 11 11 111 11 1111 I' 1 ,} 111 tl' 1111 i 1 a. is Iii 111° ilii I t :'! 1'S . , t` 111 I!1 1111 1 111 111 1111 . 1.' 1� 111 I fill IN 1 a, I ll ttlrl Illi t z ,j I ; ,I Iii :•I}Ii ILII I t L 1VIli III; 1111 1 1 111 (11 ': t 4" i / tf. 111 ,i #i t11 L',,, • '8$ S 111 - t'• 1111 • t 1 1 k . ' 1 -1 111 I �; 1111 • 1/1• • ! t �7I{, 1111 1111 1 4; 1, ,, 1 ?. `W11 .111 i } 1111,. <, 1 , ,' I: Series 640 & 740 Product Specifications Jamb Molding:Series 640-1"wide by 3/8" deep aluminum. Complete Product Specifications: Series 740- 1-5/8"wide by 1"deep aluminum. Please visit www.woodfold.com Latch:Series 640-Deadlatch with thumbturn two-sides. Panels:4-1/4"wide solid or perforated aluminum in bronze, (Other options available) clear or gold. Series 740-Keylock two sides. Panel Connectors: Panel connectors color-coordinated to (Other options available) panels. Handles:Molded plastic with finger recess. Series 640-Flexible vinyl. Width:No limitation. Series 740-Rigid vinyl with steel rods. Height: Bronze and Gold up to 8'-1". Track: 1-1/8"x 1" aluminum, dark bronze, clear or gold Clear up to 10,-1". finish. (Curvable option available) Stacking Space: 1-1/4"per foot plus 2-3/4"for lead post. Wheels:Nylon wheel on steel axle with ball bearings supplied as standard. Lead Posts:3/4"x 2-3/4"aluminum, color-coordinated to panel connectors. www.woodfold.com 0 Series 740 Page 2 of 2 S - OP IAWI \ GS Intermediate Privacy Latch f4gpk'1 Single Cremone Double Cremone Stack Dimensions Rolling Post Bolt Keylock bolt Keylock 7 I r!NOM _ ____ i :i ....., 1 i 3—S/I6• h's.' . �I '!,11(liti. Jam•0 " NI' � II �III JStacks: 1-1/4 per foot of /door, plus 2-3/4' for Lead Panel , IPost it &Sleeve I �' I�' Connectors INFORMATION Catch/Lock Options Width Custom mode to any width Magnet Magnet with strike plate Height Custom mode to 10' -r Privacy Latch Deadlatch with thumb turn one side Panels Aluminum: Solid or PA[C 1i atGd: Springlatch Springlatch with thumb turn two sides Side Channel Aluminum: Clear Keytock 1 Side Deadlotch with thumb turn one side, keyfock one side Panel Connector Rigid Vinyl: Clear Key and Single Bolt Key and single bolt lock Coordinated with side channel Key and Double Bolt Key and double bolt lock Hinge System Steel: Clear Single Cremone Single Cremone Bolt with Key Lock Wheels Ball bearing nylon wheels on steel axles Double Cremone Double Cremone Bolt with Lock Track Aluminum (straight or curvable): Clear Footbolts Locking or non locking Recessed Channel/ Aluminum (straight only): White Other Keyed Options Keyed alike, custom keyed, construction core 'Hat' Channel Contact manufacture for more details Lead, Intermediate and Jamb Aluminum: Clear Latch Deadlatch with Key Lock two sides Header Construction Detals by Others Door Weight Height Average Weight 6'-8. 10lbs. Per lineal foot 8.-1. 12lbs. Per lineal foot Job Nome: Architects Acceptance 10'-1' 15lbs. Per lineal foot Job Location: Supplier: See Wood(old Accordion Door brochure for additional details Oty. Sime/Poir Single End/Double End Left or Right Stack Width X Height Finish/Color Comments THESE SPECIFICATIONS ARE SUBJECT TO CHANGE WITHOUT NOTICE Woodfold Manufacturing, Inc. Phone: 503-357-7181 P.O. Box 346 Forest Grove, OR. 97116 Fox: 503-357-7185 http://www.woodfold.com 740 SD 6/03 Hollow Metal frames provided with full face weld only. Hollow Metal Door and Frames are provided factory primed.All finish paint is BY OTHERS BID EXCLUSIONS: Tax excluded Glass and glazing, except factory glazed wood doors. Multiple phasing of material orders and deliveries(single shipment included). Job site visits for verification of existing conditions. Repair or rework of existing materials. Bituminous coating of frames. Installation. Aluminum doors, frames and related hardware. Fees for Construction Payment Management services, ie: Textura This quote is based on providing materials as per plans and specs. McKinney Door& Hardware is willing and able to provide value engineering pricing for this project Than you for gi 'ng us the opportunity to bid this project. rian Cadena McKinney Door& Hardware 2700 N Freeway Pueblo, CO 81003 PH 719-543-3124 FAX 719-543-1921 Brian cadena@mckinneydoor.corn MCKINNEY DOOR&HARDWARE,INC. 2700 N FREEWAY PUEBLO.CO 81003 Proposal page 2 of 2 719-543-3124 FAX.719-545.9639 sn:w;.r•ca rs xc+s,u•:.:., i_.-..a..a •e vas